Disputes with Completion Dates

Disputes with Completion Dates As mentioned in the introduction, disputes associated with completion dates often become complicated due to association with different legal concepts. To fully comprehend the research subject matter, it is important to give a brief overview of such principles, as detailed further below. Most commonly the Contractors obligations in respect of time for completion of the works are expressly defined [OV1]within the terms of contract, it is yet not uncommon for the extent of such obligations to be described less definitively. While the time for completion will be expressly defined as a fixed date or a fixed period and can be easily identified, it is also essential to for the contract to provide for the mechanism of establishing completion: e.g. commencement date where completion is determined by a fixed period. Where the time for completion is ill-defined to such extent that the contracting parties intentions cannot be established or are non-existent, then the law considers time to be at large [OV2]and implies a requirement to complete the works within reasonable time. The principle of reasonable time under English Law goes back to 19th century[1], where it was established that for if a delay is not attributed to causes within a partys control, nor such party acted negligently, it will be considered that obligations are duly fulfilled. Reasonableness cannot be given a strict definition and is assessed on a case-by-case basis, taking into consideration circumstances prevailing during the period of performance[2]. Some authors on the subject view that both ordinary (e.g. site access, government permits, resource availability, etc.) and extraordinary circumstances (e.g. strikes, client variations, etc) should be taken into consideration when establishing reasonable time[3]. Occasionally, some bespoke contracts may contain time is of the essence terms. In contractual context, it has stricter meaning than its everyday application: i.e. if something isnt done swiftly, it will be too late[OV4].[4] Inclusion of such terms in a contract significantly elevates the rights and obligations to the contract, whereby failure to meet the completion date will be treated as a fundamental breach of the contract[5]. While the contract may be found repudiated, the existence of a time is of the essence provision alone may not be sufficient and qualifying rules should be applied in such circumstances[6]. Another area of significant importance in establishing whether completion date has been adhered to, is the meaning of completion itself. Ordinary meaning of completion[OV5] requires fulfilment of all obligations, which when applied in the context of entire contracts[OV6], may result in harsh consequences. It is extremely rare for construction contracts to be considered in the same manner and courts will generally take a practical view as to what constitutes completion within construction industry[7]. To reflect that position, standard construction contracts have developed various definitions for use in the industry, such as: practical[8] or substantial[9] [OV7]completion, which irrespective of the words used to describe it, are intended to reflect the courts position as summarised by Judge Newey QC[OV8]:[10] In my opinion there is no room for completion as distinct to practical completion. Because a building can seldom if ever be built precisely as required by drawings and specification, the contract realistically refers to practical completion and not completion but they mean the same. Eminent legal writers on this subject[11] concur with this view: Usually it will mean bona fide completion free of known or patent defects so as to enable the owner to enter into occupation. The words practical or substantial in the English standard forms do no more than indicate that trivial defects not affecting beneficial occupancy will not prevent completion (the more so, of course, if the contract provides for a maintenance or defects liability period) [12] Irrespective of exact term used, completion can be summarised as a significant gateway, which signifies: the transfer of risk for the care of the works from the Contractor to the Employer repossession of the site by the Employer the start of the period during which the Contractor will be liable for defects in the works the end of the Contractors liability for late completion release of retention monies from the Employer to the Contractor the end of Contractors obligation to insure the works Understanding of the above has a clear importance in resolving any disputes arising out of delay, extension of time and other time related matters. In addition to an obligation to complete the works by a specific date or within a specific time period, most contracts make specific provision for the contractor to proceed with the work and make progress with due diligence. Understanding of this term may, in first instance, appear to have only a remote connection to the subject matter. However, as shown in the next chapters, it is of significant importance when it comes to establishing the contractors responsibility when the time of completion is set at large. The courts have held that the assessment of what constitutes diligence must be based on the surrounding circumstances of each case. For example, per Lord Justice Parker[13] what is due diligence and expedition depends, of course, on the object which is sought to be achieved, who went on to explain the relation between diligence and specific contract object, time scales, complexities, etc. Similarly, in the separate Court of Appeal case of West Faulkener Associates v London Borough of Newham (1994)[14] the court found that literal interpretation, commercial logic and common sense required the contractor to proceed both regularly and diligently.[15] In the absence of an explicit due diligence obligation within a contract, some authors consider that common law implies such a term on the grounds of business effic[OV9]acy[16]. [1] Lord Watson in Hick v Raymond and Reid [1893] AC 22 [2] British Steel Corporation v Cleveland Bridge and Engineering Co. Ltd [1984] 1 All ER [3] I.N.nDuncan- Wallace in Hudsons Bilding and EngineeringÂÂ   Contracts, 11th Edn., 1995, Sweet Maxwell Ltd, p.119 [4] Oxford Dictionary of English 2nd edn., 2008, Oxford University Press [5] Carr v J.A. Berriman Pty. Ltd. [1953] ALJ 273 High Court of Australia [6] United Scientific Holdings Ltd. v Burnley Council [1977] 2 WLR 806 [7] E.g. Emson Eastern Ltd v EME Developments Ltd [1991] 55BLR 114 [8] JCT [9] ICE [10] Emson Eastern Ltd v EME Developments Ltd [1991] 55BLR 114 [11] For example B. Eggleston in Liquidated Damages and Extensions of Time, 3rd edition, 2009,ÂÂ   Wiley-Blackwell, and I.N. Duncan-Wallace in Hudsons Building and Engineering Contracts, 11th edn., 1995, Sweet Maxwell Ltd. [12] I.N. Duncan-Wallace in Hudsons Building and Engineering Contracts, 11th edn., 1995, Sweet Maxwell Ltd. p1109 [13] Greater London Council v The Cleveland Bridge Engineering Co. Ltd [1986] 34 BLR 50 [14] West Faulkener Associates v London Borough of Newham [1994] 71 BLR 1 [15] B. Eggleston in Liquidated Damages and Extensions of Time, 3rd edition, 2009, Wiley-Blackwell, p 24 [16] I.N. Duncan-Wallace in Hudsons Building and Engineering Contracts, 11th edn., 1995, Sweet Maxwell Ltd., p1125 [OV1]Insert ref. to one of the standard contracts [OV2]Insert ref. [OV3]Could expand slightly to beef up [OV4]Check later ed. Of the dictionary. Also check single or double parentheses throughout [OV5]Insert ref [OV6]Ref. [OV7]Full ref. [OV8]Pp location [OV9]Link to the next chapter?

Porter and Bogusky advertising

The move to Crispin, Porter and Bogusky advertising was one of the wisest moves that Burger King CEO Brad Blum could have made. From previously declining sales, Crispin advertising was able to change all that through its out of the box advertising campaigns. Although ultimately Burger King sales went up, it did not necessarily mean that the market and the critics were impressed.The following is a short discussion on most and least helpful of these campaigns and their impact on the potential market of Burger King. Crispin used several consumer sales promotions items to help boost the sales of Burger King. Out of those discussed in the readings, the Coq Roq campaign was least helpful. Although sales of Chicken Fries were very strong, the use of a heavy metal band and too commercialized overly focused on the promotion of the band rather than the product it was trying to sell.Worse, shortened the reach of the company to only its current target market and isolated it from the rest of its potential market, by making their advertising too specific to a particular market. Unlike the Coq Roq campaign, the Have it your way campaign was the most helpful. It was able to address the underlying desire of consumers of being made to feel individual and special. It showed consumers that their needs and wants came first, and this was portrayed by a quirky television commercial of two men in an office racing to create their own burger.In addition, the online campaign â€Å"subservient chicken,† which was connected with the have it your way campaign drew in more customers by using word of mouth, or in this case by sharing it with friends through e-mail. By this kind of promotion, Crispin was able to expand Burger Kings target market by the use of a campaign that was friendly to a wider market. By this method of advertising it accomplished what the Coq Roq campaign was unable to, that is it allowed the image of Burger King to be more â€Å"market friendly,† attracting other segments of the market.

New Questions About Life Changing Event Essay Topics Chaampionship Game Answered and Why You Must Read Every Word of This Report

New Questions About Life Changing Event Essay Topics Chaampionship Game Answered and Why You Must Read Every Word of This Report Aside from bridal dress and photoshoots, in addition, there are many activities you are able to enhance your wedding to boost the entertainment of your visitors. If you intend to travel the world or starts a company, just begin doing it even if it's only a small step. Your family and friends will still be there, and you'll continue to be able to be in touch with them through the world wide web or by phone on a normal basis. Social media ensure it is simple to craft the overall look of a terrific life. To do that, we must have the ability to take a tough look at that which we want, that which we need, that which we love and that which we hate. The very first blank page was so tough. Nevertheless, if things change unexpectedly, sometimes you just have to roll with this. Ensure the things around you're net positive. Getting the Best Life Changing Event Essay Topics Chaampionship Game Keep yourself away from devices while you're sleeping. For the best outcome, PEMF frequencies are tuned to delta-state to allow increased quality recovery utilizing a process called brainwave entrainment. Your sleep will change as you're going through menopause, that is true. Moving away from men and women you love can be quite stressful and difficult, but it doesn't need to be. So no this isn't a sect. There's a myth that in the event you build a fantastic idea people will come. Know the bullet points you want to hit and be sure you hit them. New Ideas Into Life Changing Event Essay Topics Chaampionship Game Never Before Revealed In many firms, the form of DUI, along with the seriousness of the offense, will be taken into account before hiring new employees. Otherwise, initial drunk-driving offense causes a calendar year's suspension that leads to potential havoc to an individual's job, educational pursuits, and family obligations. Not being really prepared to decide about whether to find a divorce because of emotional uncertainty is going to be a critical obstacle if you let your emotions cloud your capacity to reason or utilize logic. This item to take into account when thinking about divorce is among the key things that could lead a man or woman to a decision, 1 way or another. The Hidden Truth About Life Changing Event Essay Topics Chaampionship Game Albert Einstein Success ought to be something you don't just need to attain, but something you MUST achieve. No Third Parties It's not reasonable to pull different individuals in to support your side. Everyth ing we read said this isn't a pitch. You may only do that if you keep focused in the present on the present discussion. It usually means that if you look back on the decision you've made, the path you've taken, you wouldn't have changed what you did. Be open to the people that you meet and your conversation will grow more meaningful. Sometimes two or three conversations happening simultaneously. Unexpressed emotions won't ever die. Like a great friend and what happened to terminate the friendship. Friendship is the secret to a joyful relationship. My mother was a rather flawed woman and we had an extremely complicated relationship. Choose the change and discover what life has to provide you with! It is the largest occasion in anybody's life. The exact same is true of genuine life. At times you will experience tragedy. Moreover, there's no need to consider repairing the world as a charitable act. There's no church, no bible and no pastor who'd let you know what is wrong and what's ideal. For tourism purposes There are lots of people keen to cover a weekend close to nature with the full family and fincas usually offer you a package of a couple of days with distinctive pursuits. Some people might be pleased with a 9 to 5 or even 9 to 9 existence, but for all those who want time freedom, getting from the comfortable zone is necessary to attain this freedom. It's a means to realize your dreams. Life may throw you a curve ball from time to time and, from time to time, it may appear hopeless. It's a distinctive experience . The area where your best discomfort lies is in addition the spot where your biggest opportunity lives. It is not going to be easy to select the step out of our comfort zone, but in the very long run, you'll have considerably more freedom and happiness because of it. To prepare to acquire out of your comfort zone you have to first feel deep down that you've got to. Your comfort zone is presently expanding and when it's coupled with success each moment, you'll never need to stop.

Marketing plan of a product - 1770 Words

Executive Summary In our country there are various types of soft drink available, but Green Coconut water is rear in Bangladesh. So, we want to market Green Coconut Water. We have prepared this feasibility plan on that basis. We have assigned a name for the product as â€Å"Malala†. Since the raw materials are very much available in our country, we have decided to give the product an indigenous image. Malala is a kind of soft drink that provides the consumers with processed green coconut water in bottles. For the marketing purpose of the product we have decided to launch three product lines. The Malala would be launched in the market at 250 ml. 500 ml. and 1 Litre bottle. We have set a reasonable price for the product so that all kinds of†¦show more content†¦About 5 million people of this total number are health conscious. They spend about Tk. 500 in a month in average. Sick people: Sick people are one of our major considerations. More than 1 million children suffer from diarrhoea that need liquid food. Not only child but also the adult might suffer from those types of problems. Tourists: Every year a huge number of tourists visit Bangladesh. We want to provide them with â€Å"Malala†. General Customers: Besides the above segments, the general customers will acquire a significant portion of our target market. Competitor Analysis The major soft drinks and juice companies of current market are: Pran Groups Starship Uro Cola RC Cola Coca cola Pepsi Acme Danish Foreign Products etc. Market Research and Analysis Our company wants to develop and introduce a new Product. So, we have gathered information through in-depth interviews. We made a survey of the market to have a clear idea about our market, our customer demand, needs and wants. This information helps us to know about the current market and prospects of our new product. Market Description Bangladesh is a country of about 150 million people.. The total market size of the soft drink industry is about 20 million and day by day it is increasing. We have a spread nationwide market of different convenient product. People are nowadays very much concerned about the market and productShow MoreRelatedProduct Marketing Plan For Marketing1683 Words   |  7 PagesProduct Marketing Plan In the business, the world, marketing is the trade of introduction of inventors and corporations to the consumer. This trade will be in the regards to marketing the product and/or services also the invention. Marketing point will be conducted with a series of surveys, test groups and information collected for a target marketing segment. In these, conduct informational studies, the marketing will figure to correct target market, consumer and the supply and demand of the productRead MoreMarketing Plan For A New Product776 Words   |  4 Pages Marketing Plan for a new product Background In 1990, Mr. John and his family in the city of San Francisco had established SH confectionary which has grown to be a big franchisor with 10 stores in the State of California. SH confectioners are interested in adding new products to their product line to expand their business. In order to do so, Mr. John had came up with an idea of selling liquor flavoured chocolates named Grand Marnier in his storeRead MoreMarketing Plan For Product And The Managers1211 Words   |  5 PagesSecond, marketing helps the business find out customer needs, use different selling plan to improve the sale of the goods or services and then satisfy the needs. Marketing design the plan for the product and the managers can follow the four condition, product, price, place and promotion, means the 4Ps of marketing, to decide the final plan. Understanding the customer needs are important in marketing. Because different type of customers have different needs. Then, customer always be the main focusRead MoreMarketing Plan on Single Product3510 Words   |  15 PagesMarketing plan ON ‘Carrot chips’ (A product of Bombay Sweets Bangladesh Ltd) Address: Nestle Bangladesh Ltd. Gulshan Twr. 4th Fl., Plot 31 Rd. 53, Gulshan N C/A Dhaka, 1212 Bangladesh Fax: 880 02 988 1302 A Report ON ‘Apple chips’ Prepared by Dipock Mondal +8801916286988 Table of Contents Serial No. | Subject | Page | | Executive Summary | I | | Acknowledgement | II | | IntroductionRead MoreMarketing Plan Of A New Product1137 Words   |  5 Pageswebsites books. 2.0Historical Background It’s not too far, about one month ago we six friends were gossiping in our university. We were talking about our new term paper of marketing course. We were discussing what our topic should be. All of us gave so many ideas about our term paper objective, â€Å"Marketing Plan of a New Product†. Suddenly one of us invent the idea to production of â€Å"Date Palm Juice† in a new format which no one ever seen. All of us support the idea and it’s really nice. After thatRead MoreMarketing Plan: Applpoly Products992 Words   |  4 Pageschemist working in ApplPoly Products’ resins laboratory, had developed the new product; she attempted to convince her managers to support her new merchandise in foamed polystyrene with recognition. The position Preston works was to find new products, and to develop more profitable applications for the company; nevertheless, she faced some unforeseen difficulties because of the new product. Preston had heavy stress from her managers because she needed to find out the new products that could satisfy theRead MoreMarketing Plan For A New Product2084 Words   |  9 Pageslike a good start. Presenting a new product to the market is not just described as selling and promoting. Certainly, launching a new product needs more than just that, in orders to be highly demanded by customers. Another things also contribute to making a great product: dedicated employees, good strategy, decent information systems, exc ellent implementation, in special when it comes to introduce a new product to a highly developed market. That is where marketing should be used, as nowadays, successfulRead MoreMarketing Plan For A New Product1357 Words   |  6 PagesWhenever introducing a new product to a current market, an organization will need to prepare for challenges they may face. For this reason, Kohler will need to be smart with our promotional and advertising objectives when introducing Hygieia to the commercial and residential markets. Our objectives will focus on building awareness, creating interest, providing information, stimulating demand, and reinforcing the brand. Working with our big box retailers, we will need to work closely with channelRead MoreMARKETING PLAN FOR NEW PRODUCT4262 Words   |  18 Pagesï » ¿ASSIGNMENT ON MARKETING PLAN FOR NEW PRODUCT SUBMITTED TO: Bankim Chandra Sarker Lecturer Marketing Department, BUBT SUBMITTED BY: Rajeeb Kumar Saha ID# 13142201070 (30th) S.M Rafiqual Islam Rahat ID# 11121201529 (23rd) Mohammad Rasel ID# 12132201078(27th) MBA PROGRAM, BUBT BANGLADESH UNIVERSITY OF BUSINESS AND TECHNOLOGY Plot#77-78 # 9 Rupnagar Mrpur-2, Dhaka-1216 SUBMISSION DATE: 07-01-2015 January 07, 2015 The LecturerRead MoreNew Product Marketing Plan4260 Words   |  18 PagesSYNERGY 3-in-1 Laundry System Marketing Plan Laundry is no longer a chore with DIVA! Synergy TABLE OF CONTENTS 1.0 2.0 EXECUTIVE SUMMARY †¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦ Pg 3 SITUATION ANALYSIS †¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦...Pg 3 2.1 3.0 4.0 Target Market †¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Pg 4 NEW PRODUCT INTRODUCTION †¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Pg 5 SWOT ANALYSIS †¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦......Pg 6 4.1 4.2 4.3 4.4 Strengths †¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦.. Pg 6 Weaknesses †¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦.. Pg 7 Opportunities †¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦Ã¢â‚¬ ¦